Terms & Conditions

Terms and Conditions for L and C Construction

These Terms and Conditions (“Terms”) govern your use of L and C Construction’s website and services. By accessing our website or engaging our services, you agree to these Terms.

1. Definitions

  • Client: The person or company requesting services from L and C Construction.
  • Company: Refers to L and C Construction.
  • Services: Construction, demolition, and other related work provided by L and C Construction.

2. Service Agreement

L and C Construction agrees to provide the Client with services as outlined in a separate, signed agreement or project proposal. All work will be completed to the highest industry standards and in compliance with applicable regulations.

3. Quotes and Pricing

  • Estimates: All quotes are valid for 30 days unless otherwise specified. Any changes to the scope of work may require an updated quote.
  • Payment Terms: Payment terms, including deposits, milestones, and final payments, will be specified in the project agreement.
  • Additional Costs: Unforeseen issues, such as hidden structural problems, may incur additional charges. Clients will be informed before work on additional costs begins.

4. Client Responsibilities

  • Access to Site: The Client must provide clear access to the site to enable work to be carried out.
  • Permits and Permissions: The Client is responsible for obtaining necessary permits unless otherwise agreed.
  • Safety: Clients must ensure the site is safe for work to proceed and free of hazards.

5. Project Timelines

L and C Construction will provide estimated start and completion dates. However, timelines may be adjusted due to weather conditions, supply delays, or unforeseen circumstances.

6. Warranties and Liability

  • Workmanship Warranty: Our services are warranted for [timeframe, e.g., one year] from the completion date. This warranty covers defects due to workmanship and does not cover damage caused by misuse, neglect, or external factors.
  • Liability: L and C Construction will not be liable for indirect, incidental, or consequential damages. Our liability is limited to the cost of the services provided.

7. Termination and Cancellation

  • By the Client: The Client may cancel the project prior to commencement. If a deposit has been paid, a portion may be non-refundable, depending on the costs already incurred.
  • By L and C Construction: We reserve the right to terminate the project if the Client breaches any terms or if the site conditions make it unsafe or impossible to continue work. Refunds for incomplete work will be handled on a case-by-case basis.

8. Force Majeure

L and C Construction will not be liable for delays or non-performance caused by events beyond our control, such as natural disasters, strikes, or supply chain disruptions.

9. Governing Law

These Terms are governed by the laws of [your jurisdiction, e.g., England and Wales], and any disputes will be resolved in the courts of [your jurisdiction].

10. Amendments

L and C Construction reserves the right to amend these Terms at any time. Clients will be notified of changes, and the most current version will always be available on our website.

11. Contact Information

For questions or concerns regarding these Terms, please contact us with the form below: